ALLcrimesfood&drugstaxestelecomcommercehealthconservationtransportationagricultureveteransbrowse all titles »
0

28 U.S.C. § 1499 — Liquidated damages withheld from contractors under chapter 37 of title 40

submitted 78 years ago by ch. 646 to r/title-28-JUDICIARY-AND-JUDICIAL-PROCEDURE · 32 words · no verdicts yet

in plain englishAI-generated · not legal advice

The Court of Federal Claims may decide claims for liquidated damages withheld from contractors or subcontractors under a specified title 40 provision.

The Court of Federal Claims may decide and enter judgment on a claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.
the actual law source: uscode.house.gov ↗public domain

The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.

Source credit: (June 25, 1948, ch. 646, 62 Stat. 942; Pub. L. 87–581, title II, § 202(a), Aug. 13, 1962, 76 Stat. 360; Pub. L. 97–164, title I, § 133(e)(1), (2)(A), Apr. 2, 1982, 96 Stat. 40, 41; Pub. L. 101–650, title III, § 325(b)(7), Dec. 1, 1990, 104 Stat. 5121; Pub. L. 102–572, title IX, § 902(a)(1), Oct. 29, 1992, 106 Stat. 4516; Pub. L. 107–217, § 3(g)(3), Aug. 21, 2002, 116 Stat. 1299; Pub. L. 109–284, § 4(2), Sept. 27, 2006, 120 Stat. 1211.)

history & why it existsrecord from the source credit
  • 1948Enacted · Act of June 25, 1948, ch. 646 · 62 Stat. 942
  • 1962Amended · Pub. L. 87-581 · 76 Stat. 360
  • 1982Amended · Pub. L. 97-164 · 96 Stat. 40, 41
  • 1990Amended · Pub. L. 101-650 · 104 Stat. 5121
  • 1992Amended · Pub. L. 102-572 · 106 Stat. 4516
  • 2002Amended · Pub. L. 107-217 · 116 Stat. 1299
  • 2006Amended · Pub. L. 109-284 · 120 Stat. 1211

A history note hasn’t been published yet. The record shows enactment by ch. 646 on 1948-06-25.

all 0 arguments · sorted by: best

0/280

no arguments yet — make the first case